Rank-Order Analysis of Factors Causing Claims on Road Construction Projects in Botswana

Aderemi Y. Adeyemi, Olefile Segwabe

Abstract


Claims are considered to be one of the most serious disruptive forces to successful project delivery in the construction industry. In a small developing economy like Botswana, it is germane to identify the sources and the frequency of occurrence of claims so that the burden of project cost overrun, a hallmark of the country’s construction industry is substantially reduced. Detailed literature review and preliminary field investigations were used to identify causes of claims related to road construction projects. The study identified six major types of claim and twenty seven causes of claims. Using questionnaire as research instrument, respondents (construction industry major stakeholders i.e. clients, consultants and contractors) were asked to rank the frequency of occurrence of the types and causes of claims in road construction projects on a Likert-type scale. Relative importance index (RII) method was used to analyze the data collected from the questionnaire survey. The analysis was carried out for each group of respondents and on the overall results (all the parties combined). A total of 27 useful responses made up of nine clients, ten consultants and eight contractors) were analyzed. Findings indicated that the clients and consultants specified delay claims followed by extra work claims were the most frequent type of claims in the construction of roads in Botswana. Contractors perceived differing site conditions followed by delay claims as the most frequent type of claims. From the overall response, delay claims were ranked first followed by extra work claims. Acceleration claims were ranked least. The top five most frequent causes of claims based on overall ranking were: variation in quantities, design errors, poor site management and supervision by contractor, ineffective planning and scheduling of project by contractor, and low price of contract due to high competition. Construction industry research in Botswana has never looked into the issue of claims and yet it is one of the hidden sources of construction project failure in the country. It is perceived that hedging against the most adverse causes of claims will stem the tide of incessant cost overrun, litigation and project abandonment on road projects in Botswana.


References


Adeyemi, A., Mselle, P. Kashiwagi D. and Kashiwagi, J. (2011). A new approach to the delivery of construction in Botswana. Journal of Civil Engineering and Architecture, 55(7), 606-617.

Adeyemi, A. Y. and Kashiwagi, D. T. (2014). Non-Sustainability of low-bid infrastructure, procurement system: lessons for developing countries. International Journal of Engineering and Innovative Technology (IJEIT). 4 (6), 246-251.

Adeyemi, A. Y. Oladele, A. S. and Kashiwagi, D. T. (2014). Linking PIPS to sustainable consumptions in African transportation sector facilities projects. International Journal of Transportation Technology Transfer (T2) in Africa. 1(2), 11-26.

Adeyemi, A. Y., Samman, J. and Mselle, P. C. (2015). Traditional procurement system as a source of unsustainable development: empirical evidence from public infrastructure projects delivery in Botswana. Proceedings of the International Conference on Infrastructure Development and Investment Strategies for Africa (DII-2015), 16th -18th September, Livingstone, Zambia, 430-437.

Aibinu, A.A and Jagboro, G.O. (2002). The effects of construction delays on project delivery in Nigerian construction industry. International Journal of Project Management. 20(8), 593-599.

AlKass, S., Mazerolle, M. and Harris, F. (1996). Construction delay analysis techniques. Construction Management and Economics. 14(5), 375-394.

Al-Khalil, M.I. and Al-Ghafly, A.M (1999). Delay in public utility projects in Saudi Arabia. International Journal of Project Management. 17(2), 101-106.

Al-Momani, H.A. (2000). Construction delay: A quantitative analysis. International Journal of Project Management. 18(1), 51-59.

Alnaas, K. A. A., Khalil, A. H. H. and Nassar, G. E. (2014). Guideline for preparing comprehensive extension of time (EoT) claim. Housing and Building National Research Center (HBR) Journal. 10, 308-316.

Arditi, D and Pattanakitchamroon, T. (2006). Selecting a delay analysis method in resolving construction claims”. International Journal of Project Management. 24(2), 145-155.

Assaf, S.A and Al-Hejji, S.A.H. (2006). Causes of delay in large construction projects. International Journal of Project Management. 24(4), 349-357.

Assaf, S.A., Al-Khalil, M. and Al-Hazmi, M. (1995. Causes of delay in large building construction projects. Journal of Management in Engineering. 11(2), 45-50.

Bakhary, N. A., Adnan, H. Ibrahim, A. (2015). A study of construction claim management problems in Malaysia. Procedia Economics and Finance. 23, 63 – 70.

Braimah, N. (2013).Approaches to delay claims assessment employed in the UK construction industry. Buildings. 3, 598-620.

Chaphalkar, N. and Iyer, K. C. (2014). Factors influencing decisions on delay claims in construction contracts for Indian scenario. Australasian Journal of Construction Economics and Building.14 (1), 32-44.

Enshassi, A. Mohamed, S. and El-Ghandour, S. (2009). Problems associated with the process of claim management in Palestine. Engineering, Construction and Architectural Management. 16(1), 61 – 72.

Hadikusumo, B. H. W. and Tobgay, S. (2015). Construction claim types and causes for a large-scale hydropower project in Bhutan. Journal of Construction in Developing Countries. 20(1), 49–63.

Hardjomuljadi, S.(2010), The main causal factors of construction claims under FIDIC contract in Indonesia. Paper presented at FIDIC-JICA International Construction Management Training, 26th – 29th July, Jakarta, Available at: http://ssrn.com/abstract=1898436.

Hassanein, A.A.G. and Nemr, W. E. (2008). Claims management in the Egyptian industrial construction sector: a contractor's perspective. Engineering, Construction and Architectural Management. 15(5) 456 – 469.

Ho, S. and Liu, L. (2004). Analytical model for analyzing construction claims and opportunistic bidding. Journal of Construction Engineering and Management. 130(1), 94–104.

Iyer, K.C., Chapkhalkar, N.B. and Joshi, G.A. (2008). Understanding time delay disputes in construction contracts, International Journal of Project Management. 26, 174–184.

Kamble, K. S. and Kambekar, A. R. (2013). Analysis of factors contributing delays and claims in construction projects. International Journal of Research in Engineering and Technology, (Special Issue, IC-RICE Conference). 2(1), 390-394.

Klee, Lukas, K. (2013). Management of contractor's claims in construction projects, Littera Scripta 1/2013, roè. 6, è. 1. Available at SSRN: http://ssrn.com/abstract=2405813.

Love, P.E.D., Davis, P.R., Baccarini, D., Wilson, G. and Lopez, R. (2008). Procurement selection in the public sector: A tale of two states, Paper Presented at 3rd International Conference of the Cooperative Research Centre for Innovation, Clients Driving Innovation: The Benefits of Innovation, Gold Coast, Australia, 12-14 March.

Manavazhi M.R and Adhikari. D.K, (2002). Material and equipment procurement delays in highway projects in Nepal. International Journal of Project Management. 20(8), 627-632.

Mohsin, M. A. (2012). Claim analysis of construction projects in Oman. International Journal on Advance Science Engineering Information Technology. 2 (2), 73-78.

Odeh, A.M and Battaineh, H.T. (2002). Causes of construction delay: Traditional contracts. International Journal of Project Management. 20(1), 67-73.

Odeyinka, H.A and Yusif, A. (1997). The causes and effects of construction delays on completion cost of housing projects in Nigeria. Journal of Financial Management and Property Construction. 2(3), 31-44.

Preez, O.D. (2014). Conciliation: A founding element in claims management. Procedia – Social and Behavioral Sciences. 119, 115 – 123.

Sambasivan, M. ND Soon, W.Y. (2007). Causes and effects of delays in Malaysian construction industry. International Journal of Project management, 25(5), 517-526.

Semple, C., Hartman, F.T and Jergeas, G. (1994). Construction claims and disputes: causes and cost/time overruns. Journal of Construction Engineering and Management, ASCE. 120(4), 785-795.

Segwabe, O. (2008). An evaluation of road construction claims in Botswana, Unpublished MPM Thesis, Department of Civil Engineering, University of Botswana.

Shrestha, P. P., Meyer, N., Shrestha, K.(2014). Delay claims analysis in construction industry. Proceedings of Associated School of Construction 50th International Conference, Washington, D.C, March 26-28, 2014. Available on: http://ascpro.ascweb.org/chair/paper/CPRT183002014.pdf.

Yoke-Lian, L. S. Hassim, S. Muniandy, R. and Mee-Ling, T. (2012). The assessment of applications for extension of time claims in Malaysian construction industry. IACSIT International Journal of Engineering and Technology. 4(4), 446-450.

Yusuwan, N. M. and Adnan, H. (2013a). Issues Associated with extension of time (EoT) claim in Malaysian construction industry. Procedia Technology. 9, 740 – 749.

Yusuwan, N. M. and Adnan, H. (2013b). Assessing extension of time application in Malaysian construction industry: Views from professionals. Procedia - Social and Behavioral Sciences.105, 54 – 63.

Zaneldin, K. E. (2006). Construction claims in United Arab Emirates: Types, causes and frequency. International Journal of Project Management. 24(4), 453-459.


Full Text: PDF

Refbacks

  • There are currently no refbacks.